Terms & Conditions

Effective Date: July 09, 2026

Welcome to Glazecraft Infrastructure. By accessing or using our website, you agree to comply with and be bound by the following Terms & Conditions. Please read them carefully before using our website or requesting our services.

1. Acceptance of Terms

By accessing this website, you acknowledge that you have read, understood, and agreed to these Terms & Conditions. If you do not agree with any part of these terms, please do not use this website.

2. Services

Glazecraft Infrastructure provides professional solutions including but not limited to:

Facade Solutions
ACP Cladding
HPL Cladding
Structural Glazing
Curtain Wall Glazing
Spider Glazing
Patch Fittings
Glass Partitions
Glass Railings
Skylights
Shower Cubicles
Automatic Glass Doors
Pergola Glass
uPVC Windows
Aluminium Windows
uPVC Doors
Aluminium Doors
Domal Windows & Doors
uPVC & Aluminium Partitions

All services are subject to project evaluation, technical feasibility, site conditions, and mutually agreed commercial terms.

3. Quotations

All quotations provided by Glazecraft Infrastructure:

Are based on the information available at the time of preparation.
May change if project requirements change.
Do not constitute a legally binding agreement until officially accepted by both parties.
May include validity periods specified within the quotation.

4. Project Execution

Project timelines depend on:

Site readiness
Material availability
Design approvals
Weather conditions
Client approvals
Unforeseen circumstances beyond our control

Estimated completion dates are provided in good faith but are not guaranteed unless specifically agreed in writing.

5. Client Responsibilities

Clients agree to:

Provide accurate project information.
Ensure site accessibility.
Obtain required statutory approvals where applicable.
Make scheduled payments on time.
Cooperate during project execution.

Any delays caused by the client may affect project schedules.

6. Payments

Payment terms will be specified in the quotation or agreement.

Delayed payments may result in:

Suspension of work
Delay in material procurement
Additional charges where applicable

7. Intellectual Property

All content available on this website including:

Logos
Images
Text
Graphics
Icons
Designs
Layouts
Documents

are the property of Glazecraft Infrastructure unless otherwise stated and may not be copied, reproduced, distributed, or modified without prior written permission.

8. Website Usage

Users agree not to:

Attempt unauthorized access to the website.
Upload malicious software.
Disrupt website functionality.
Misuse contact forms.
Copy website content without permission.

9. Limitation of Liability

Glazecraft Infrastructure shall not be liable for:

Indirect or consequential damages.
Loss of business or profits.
Website downtime.
Third-party service interruptions.
Delays caused by circumstances beyond reasonable control.

10. Third-Party Links

Our website may contain links to third-party websites for your convenience.

We do not control or endorse the content, privacy practices, or services provided by third-party websites.

11. Warranty

Warranty terms, if applicable, will be specified separately in the project agreement or quotation.

Website content is provided for general informational purposes and does not constitute professional engineering or construction advice.

12. Changes to Terms

Glazecraft Infrastructure reserves the right to modify these Terms & Conditions at any time without prior notice.

Continued use of the website after changes are published constitutes acceptance of the updated Terms.

13. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India.

Any disputes arising out of these Terms shall be subject to the exclusive jurisdiction of the courts located in Bengaluru, Karnataka.

14. Contact Us

If you have any questions regarding these Terms & Conditions, please contact us.

Glazecraft Infrastructure

Phone: +91 7090777176 / +91 9513858111

Email: info@glazecraftinfra.in

Address: Bengaluru, Karnataka, India